Terms of Service

Masonry Contractors of Corpus Christi (hereinafter "Contractor") agrees to provide masonry services as outlined in the written estimate or contract provided to the Client. The scope of work, materials, timeline, and pricing are detailed in the signed proposal or contract agreement.

Any work performed outside the agreed-upon scope will be considered a change order and requires written authorization from the Client before work begins. Change orders will include updated pricing and timeline adjustments.

The Contractor reserves the right to refuse work that violates building codes, poses a safety hazard, or is deemed structurally unsound. If such conditions are discovered during the project, the Contractor will notify the Client immediately and provide recommendations for corrective action.

All estimates provided by Masonry Contractors of Corpus Christi are provided at no cost and with no obligation to proceed. Estimates are valid for 30 days from the date of issue unless otherwise specified in writing.

Pricing is based on the information provided by the Client at the time of estimate. If actual site conditions differ materially from those described during the estimate consultation, the Contractor may provide a revised quote reflecting the new scope of work.

Estimates include labor, standard materials, and equipment as specified. Additional costs such as permits, inspections, debris removal, or unforeseen structural issues are not included unless explicitly stated in the written proposal.

All prices are in U.S. dollars and do not include applicable Texas sales tax unless otherwise noted. The Client is responsible for all applicable taxes.

Payment Schedule: Payment terms will be outlined in the signed contract. Typically, a deposit is required to secure the project start date, with the balance due upon project completion or as specified in the contract.

Accepted Payment Methods: Masonry Contractors of Corpus Christi accepts cash, check, credit card, and electronic bank transfer. Payment method details will be provided in the contract.

Late Payment: If payment is not received by the due date specified in the contract, the Contractor may suspend work until payment is made. Late payments may incur a fee of 1.5% per month on the outstanding balance or the maximum allowed by Texas law, whichever is lower.

Non-Refundable Deposits: Deposits are non-refundable once work has commenced or materials have been ordered, unless the Client cancels the project in writing at least 14 days before the scheduled start date.

Invoicing: Invoices will be provided upon completion of work or as specified in the payment schedule. Invoices must be paid within the timeframe outlined in the contract.

The Contractor will make reasonable efforts to complete the project within the estimated timeline provided in the contract. However, timelines are estimates and not guaranteed due to factors beyond the Contractor's control.

Causes of Delay: The following circumstances may delay project completion: adverse weather conditions, material shortages or delays, permit or inspection delays, site access issues, discovery of unforeseen structural or site conditions, or requests for changes to the scope of work.

Weather Delays: Masonry work cannot be performed during heavy rain, freezing temperatures, or extreme heat conditions that compromise the integrity of the work. Weather-related delays will not result in additional charges but may extend the project timeline.

Client-Caused Delays: If the Client requests changes to the scope, schedule, or specifications after work has commenced, the Contractor will provide a revised timeline and may adjust pricing to account for the delay and additional work.

The Contractor is not liable for delays caused by factors outside its reasonable control. Delays do not entitle the Client to cancel the contract or withhold payment.

Workmanship Warranty: Masonry Contractors of Corpus Christi warrants that all work will be performed in a professional and workmanlike manner in accordance with industry standards and applicable building codes. The Contractor provides a one-year warranty on labor and workmanship from the completion date.

Material Warranties: All materials used are warranted by the manufacturer. The Contractor will pass through any manufacturer warranties that apply. Specific material warranties will be provided at the time of project completion.

Warranty Coverage: The one-year workmanship warranty covers defects in labor such as improper mortar joints, structural issues caused by poor installation, or workmanship that fails to meet industry standards. The warranty does not cover normal wear and tear, environmental damage, or damage caused by improper maintenance.

Warranty Exclusions: This warranty does not cover damage caused by: acts of nature or weather, improper maintenance or care by the Client, modifications made by parties other than the Contractor, or damage resulting from structural issues present before the work began.

Warranty Claims: To file a warranty claim, the Client must contact the Contractor in writing within 30 days of discovering the defect. The Contractor will evaluate the claim and, if valid, will repair or replace the defective work at no additional cost to the Client.

Site Access: The Client agrees to provide the Contractor and its crew safe and reasonable access to the work site during scheduled work hours. The Client is responsible for marking any underground utilities (gas, electric, water, etc.) before work begins.

Property Protection: While the Contractor will take reasonable precautions to protect adjacent property, the Client is responsible for identifying any items or areas that require special protection. The Client should remove valuable items or decorations from the work area.

Permits & Inspections: The Client is responsible for obtaining any required permits and scheduling inspections unless otherwise agreed to in writing. The Contractor will coordinate with inspectors and provide access as needed.

Accurate Information: The Client agrees to provide accurate information regarding the project site, existing structures, underground utilities, and any special conditions that may affect the work. Inaccurate information may result in delays or additional costs.

Change Requests: All requests for changes to the scope of work must be submitted in writing and approved by the Contractor before work proceeds. Verbal change requests will not be honored.

Contractor Insurance: Masonry Contractors of Corpus Christi maintains comprehensive liability insurance and workers' compensation insurance as required by Texas law. Proof of insurance can be provided upon request.

Client Insurance: The Client is responsible for maintaining homeowners or commercial property insurance. The Client should verify that their insurance covers masonry work and any related claims.

Liability Limitations: The Contractor's liability for any claims arising from this agreement is limited to the total contract price. In no event shall the Contractor be liable for indirect, incidental, consequential, or punitive damages, including loss of use, loss of profits, or property damage beyond the scope of the contracted work.

Assumption of Risk: The Client acknowledges that masonry work involves inherent risks and assumes all risks associated with the project unless caused by the Contractor's negligence or willful misconduct.

Damage Claims: Any claims for damage must be reported in writing to the Contractor within 30 days of discovery. Failure to report timely may result in forfeiture of the claim.

Informal Resolution: In the event of a dispute, the Client agrees to contact the Contractor in writing to attempt to resolve the matter informally. The Contractor will respond within 10 business days.

Mediation: If informal resolution fails, the parties agree to attempt mediation before pursuing legal action. Each party will bear its own mediation costs unless otherwise agreed.

Governing Law: This agreement is governed by and construed in accordance with the laws of the State of Texas, without regard to conflicts of law principles.

Jurisdiction & Venue: Any legal action or proceeding arising from this agreement shall be brought exclusively in the state or federal courts located in Nueces County, Texas. Both parties consent to the jurisdiction and venue of these courts.

Arbitration Option: Either party may elect binding arbitration for disputes exceeding $5,000. If arbitration is elected, both parties agree to submit to binding arbitration under the American Arbitration Association (AAA) rules. The arbitration shall take place in Corpus Christi, Texas.

Attorney Fees: In any legal proceeding, the prevailing party shall be entitled to recover reasonable attorney fees and court costs from the non-prevailing party.

Client Cancellation: The Client may cancel this agreement in writing at least 14 days before the scheduled start date with no penalty other than forfeiture of the deposit. Cancellations made within 14 days of the start date or after work has commenced may result in additional charges for materials ordered and time expended.

Contractor Termination: The Contractor may terminate this agreement if: (1) the Client fails to pay deposits or invoices when due; (2) the Client requests work that violates building codes or safety standards; (3) the Client is abusive or threatens the Contractor or crew; or (4) site conditions make the work impossible or unsafe.

Termination Procedures: Termination must be communicated in writing. Upon termination, the Client remains responsible for payment of all work completed to date, materials ordered, and reasonable costs incurred by the Contractor.

Work Stoppage: If the Client fails to pay invoices when due, the Contractor may suspend work until payment is received. Work will not resume until the account is current.

Safety Standards: All work will be performed in compliance with OSHA regulations and Texas construction safety standards. The Contractor maintains a safe work environment and requires all crew members to follow safety protocols.

Client Conduct: The Client agrees not to interfere with the work, remove safety barriers, or operate any Contractor equipment. The Client and any third parties on site must comply with all safety instructions provided by the Contractor.

Hazardous Materials: If hazardous materials (asbestos, lead paint, etc.) are discovered on the site, work will stop and the Client will be notified. The Client is responsible for remediation of hazardous materials by licensed professionals before work can resume.

Site Cleanup: The Contractor will remove debris generated by the masonry work and leave the site clean at the end of each work day. General site cleanup and removal of pre-existing debris is the Client's responsibility unless otherwise specified in the contract.

Pets & Children: For safety reasons, the Client agrees to keep pets and children away from the active work site during work hours.

Permit Responsibility: The Client is responsible for determining whether permits are required for the project. The Contractor can advise on typical permit requirements but does not guarantee that permits will or will not be required.

Permit Coordination: If permits are required, the Contractor can coordinate with the city/county and assist with the permit application process. Permit fees are the Client's responsibility unless otherwise specified in the contract.

Code Compliance: All work will be performed in compliance with the current International Building Code (IBC), the Texas Building Code, and local Corpus Christi building codes and ordinances.

Inspections: The Client is responsible for scheduling required inspections. The Contractor will provide access for inspections and will correct any deficiencies noted by the building inspector at no additional cost if the deficiency is due to the Contractor's work.

Code Changes: If local building codes or regulations change after the contract is signed and affect the project, the Contractor will notify the Client and provide a revised estimate if necessary.

Change Order Process: Any changes to the scope of work, materials, or timeline must be documented in a written change order signed by both the Client and the Contractor before work proceeds.

Pricing Adjustments: Change orders will include any adjustments to pricing and timeline. Verbal change requests will not be honored and do not authorize additional work.

Site Conditions: If unforeseen site conditions are discovered during work (e.g., underground obstacles, structural issues, soil conditions), the Contractor will notify the Client and provide options for addressing the condition, which may include additional costs.

Material Substitutions: If specified materials are unavailable, the Contractor will propose a suitable alternative and obtain Client approval before proceeding. Substitutions may affect pricing and timeline.

Client Information: The Contractor will maintain the confidentiality of Client contact information and project details. Client information will not be shared with third parties without consent except as required by law.

Project Photography: The Contractor may photograph completed projects for portfolio and marketing purposes unless the Client specifically requests otherwise in writing.

References: The Client agrees that the Contractor may use the Client's name and project details as a reference for future clients unless the Client requests otherwise in writing.

Complete Agreement: This Terms of Service, along with the signed contract and estimate, constitutes the entire agreement between the Client and the Contractor regarding the masonry services. All prior negotiations, representations, and agreements are superseded by this agreement.

Amendments: No modifications or amendments to this agreement are valid unless made in writing and signed by both parties.

Severability: If any provision of this agreement is found to be invalid or unenforceable, the remaining provisions will continue in full force and effect.

Waiver: The failure of either party to enforce any right or provision of this agreement does not constitute a waiver of that right or provision.

For questions regarding these Terms of Service or to report a legal concern, please contact: